NSW Caselaw
New South Wales Supreme Court
CITATION : Macquarie International Health Clinic Pty Ltd v Sydney South West Area Health Service [2008] NSWSC 738
HEARING DATE(S) : 06.02.06, 07.02.06, 08.02.06, 09.02.06, 10.02.06, 13.02.06, 14.02.06, 15.02.06, 16.02.06, 17.02.06, 20.02.06, 21.02.06, 22.02.06, 23.02.06, 27.02.06, 28.02.06, 01.03.06, 02.03.06, 03.03.06, 06.03.06, 07.03.06, 08.03.06, 09.03.06, 10.03.06, 21.08.06, 22.08.06, 23.08.06, 24.08.06, 25.08.06, 28.08.06, 29.08.06, 30.08.06, 31.08.06, 01.09.06, 04.09.06, 05.09.06, 06.09.06. 07.09.06, 08.09.06, 29.01.07, 30.01.07, 31.01.07, 01.02.07, 02.02.07, 12.02.07, 13.02.07, 14.02.07, 15.02.07, 16.02.07, 19.02.07, 20.02.07, 21.02.07, 22.02.07, 23.02.07, 26.02.07, 28.02.07, 01.03.07, 02.03.07, 05.03.07, 06.03.07, 07.03.07, 08.03.07, 09.03.07, 26.03.07, 27.03.07, 28.03.07, 29.03.07, 30.03.07, 02.04.07, 03.04.07, 04.04.07, 05.04.07, 30.04.07, 01.05.07, 02.05.07, 03.05.07, 04.05.07, 14.05.07, 15.05.07, 16.05.07, 24.05.07, 25.05.07, 31.05.07, 22.06.07, 06.07.07, 28.05.08
JUDGMENT DATE : 23 July 2008
JUDGMENT OF : Nicholas J
DECISION : Par 667
CATCHWORDS : CONTRACT – agreements to lease real property and construct a private hospital and car park thereon – termination of agreement – whether contractor in default of agreements by reason of failure to complete car park and substantially commence construction of hospital – whether contractor in default by reason of failure to pay rent and other monies – whether agreements excluded common law right to terminate - whether termination notices under agreements valid – whether giving notices of default and termination in breach of express term of utmost good faith - CONVEYANCING – leases – whether termination notices invalid under s 129 Conveyancing Act 1919 – whether amounts payable under agreements were rent within s 129(8) - whether defaults established – whether landlord entitled to terminate and re-enter - EQUITY – relief against forfeiture – whether termination of lease unconscionable – whether grant of relief would attain primary object of agreement – whether claim for relief against forfeiture established
We try to embed the page this law was scraped from. If the site blocks framing, you still get the link and a local excerpt.
Last checked with source on —
Checking whether the official page can be embedded…
Plain-English simplify of this law: a short summary, key points, and both sides of the argument. Generated on first view via Replicate, then cached. Vote on what helps your study.
No study brief is cached for this law yet. Sign up to generate a plain-English brief.
Sign up to generate